Legal Notices for May 20, 2015

Posted on May 20, 2015

NOTICE TO BIDDERS
CONCRETE APRON REHABILITATION at
PERRY FOLEY AIRPORT
TAYLOR COUNTY, FLORIDA
Notice is hereby given that Taylor County will receive sealed bids at the Taylor County Board of County Commissioners, Attn: Clerkís Office, 108 East Jefferson Street, Perry, Florida 32347 (850-838-3506) until          4 pm    local time on  Friday, June 19, 2015 , for the Concrete Apron Rehabilitation project at the Perry Foley Airport, Perry, Fl. Bids must be submitted in a sealed enveloped clearly marked ìBID ENCLOSED: CONCRETE APRON REHABILITATION; PERRY FOLEY AIRPORT.î  Bids will be opened at the Taylor County Board of Commissioners meeting to be held at the Taylor County Administration Complex, 201 East Green Street, Perry, Florida on  Tuesday, June 23, 2015  at 6:00 pm.  Bids will be publicly opened and read aloud.
The project consists of providing all labor, materials, machinery, tools, equipment and other means of construction necessary and incidental to the completion of the work shown on the plans and described in these specifications including, but not necessarily limited to the following:
Removal and replacement of concrete joints, removal and replacement of damaged concrete pavement, and other miscellaneous concrete rehabilitation work.

The contract time for substantial completion of the work included shall be   110    calendar days from the date of the “Notice to Proceed (NTP).”  The final project completion shall be  90  calendar days from the date of the “Notice to Proceed (NTP).”

Beginning on  Tuesday, May 19, 2015 , drawings, specifications, and project documents may be examined by appointment at the Airport Terminal Building of the Perry Foley Airport at 511 Industrial Park Drive, Perry, Florida 32348.  Appointments may be made by calling Bill Roberts at Perry Foley Airport at 850-838-3519.   Beginning on  Tuesday, May 19, 2015  , digital copies of the above documents may be obtained from the offices of AVCON, INC., 320 Bayshore Drive, Suite A, Niceville, Florida, 32578, (850) 678-0050, upon payment of a non-refundable fee of thirty dollars ($30.00) payable to AVCON, INC. for each set of project documents obtained. A hard copy of the above documents may be provided at an additional charge.

Bid security in the amount of at least five percent (5%) of the total quote must be submitted with the quote. The quote security may be either a certified check or a proposal guaranty bond executed by a surety company authorized to do business in the State of Florida. Quote security shall be made payable to Taylor County. The successful contractor must be able to furnish proof of required insurance, a 100% Performance Bond, and a 100% Labor and Materials Payment Bond, and shall begin execution of this contract within five (5) calendar days following the date of the Notice to Proceed.
Funding for this project is being provided by the Federal Aviation Administration and the Florida Department of Transportation and will be subject to all applicable requirements of the Federal Aviation Administration and U.S. Department of Transportation grant assurances.
The successful contract will be required to comply with all provisions of the Federal Government Equal Employment Opportunity clauses issued by the Secretary of Labor on May 21, 1968 and published in the Federal Register (41CFR Part 60-1, 33 F.2 7804). Wages paid to employees must comply with the minimum established by the U.S. Department of Labor Wage Determination. The successful contractor must comply with the Davis-Bacon Act, Copeland Act (Anti-Kickback Act), the Occupational Safety and Health Act, the Contract Work Hours and Safety Standards Act (CWHSSA), Title VI of the Civil Rights Act of 1964 and Executive Order 11246.
Taylor County has an approved Disadvantaged Business Enterprise (DBE) Program for Airport Improvement Program projects which the successful contract must comply with. The DBE participation goal for this project is 4.78% and compliance requirements are listed in the project documents.
A non-mandatory PreBid Conference will be conducted at the Terminal Building of the Perry Foley Airport at 511 Industrial Park Drive, Perry, Florida 32348 on Wednesday, May 27, 2015    at  10:00   a.m. local time (EDT).  Questions relating to the Project Documents will be answered at that time.  Attendance by prospective prime contractors is strongly recommended.
The Taylor County Board of County Commissioners reserves the right, it its sole and absolute discretion, to reject, to cancel, or withdraw this bid at any time and waive any irregularities in the bid process. The County reserves the right to award any contract to the respondent which it deems to offer the best overall service; therefore, the County is not bound to award any contract based on the lowest quoted price. The County, in its sole and absolute discretion, also reserves the right to waive any minor defects in the process and to accept the bid deemed to be in the Countyís best interest. No faxed Proposals will be accepted.
OWNER’S CONTACT:
Melody Cox
County Grants Administrator
Taylor County Board of County Commissioners
201 East Green Street
Perry, Florida 32347
Tel:  850-838-3553
Fax: 850-838-3563
ENGINEER’S CONTACT:
John Collins, P.E.
Project Manager
AVCON, INC.
320 Bayshore Drive, Suite “A”
Niceville, Florida 32578
Tel:  850-678-0050
Fax: 850-678-0040
All bids should be addressed as follows:
BID ENCLOSED: CONCRETE APRON REHABILITATION
PERRY FOLEY AIRPORT
Taylor County Board of County Commissioners
Attention: Clerk’s Office
108 East Jefferson Street
Perry, Florida 32347
5/20

IN THE CIRCUIT COURT OF THE THIRD JUDICIAL CIRCUIT IN AND FOR TAYLOR COUNTY, FLORIDA
CASE NO.:  13-CA-000601
U.S. BANK NATIONAL ASSOCIATION, AS TRUSTEE FOR MASTR ASSET BACKED SECURITIES TRUST 2006-AM2, MORTGAGE PASS-THROUGH CERTIFICATES, SERIES 2006-AM2,
Plaintiff,
v.
JOHN DAVID GALLAGHER, ET AL.,
Defendants.
_______________/
NOTICE OF SALE
NOTICE IS HEREBY GIVEN that pursuant to a Final Judgment of Foreclosure dated May 14, 2015, and entered in Case Number 2013-CA-000601 of the Circuit Court of the Third Judicial Circuit in and for Taylor County, Florida, wherein U.S. BANK NATIONAL ASSOCIATION, AS TRUSTEE FOR MASTR ASSET BACKED SECURITIES TRUST 2006-AM2, MORTGAGE PASS-THROUGH CERTIFICATES, SERIES 2006-AM2, is the Plaintiff, and JOHN DAVID GALLAGHER, ET AL are the Defendants, Annie Mae Murphy as the Clerk of the Circuit Court will sell the real property situated in Taylor County, Florida, more particularly described as:
COMMENCE AT THE NORTH WEST CORNER OF CEDAR ISLAND BAfflA UNIT A SUBDIVISION RECORDED IN PLAT BOOK 1, PAGE 113, PUBLIC RECORDS OF TAYLOR COUNTY, FLORIDA. RUN SOUTH 11 DEGREES 12′ 18″ WEST, 40.0 FEET TO THE SOUTH RIGHT-OF-WAY LINE OF THE CEDAR ISLAND ROAD, THENCE RUN NORTH 78 DEGREES 47′ 42″ WEST ALONG THE SAID RIGHT-OF-WAY LINE OF SAID ROAD 629.35 FEET, THENCE RUN SOUTH 08 DEGREES 13′ 18″ WEST 202.75 FEET FOR A POINT OF BEGINNING FROM SAID POINT OF BEGINNING RUN NORTH 08 DEGREES 13′ 18″ EAST 202.75 FEET, THENCE RUN SOUTH 78 DEGREES 47′ 42″ EAST 70 FEET, THENCE RUN SOUTH 08 DEGREES 13′ 18″ WEST APPROXIMATELY 224 FEET TO MEAN HIGH TIDE LINE OF THE GULF OF MEXICO, THENCE MEANDERING WESTERLY ALONG THE SAID MEAN HIGH TIDE LINE BACK TO THE POINT OF BEGINNING.
PROPERTY ADDRESS: 195 Cedar Island Drive, Perry, Florida 32348
at a public sale, beginning at 11:00 a.m. EST, on July 21, 2015, to the highest and best bidder for cash, at the Taylor County Courthouse; 108 N. Jefferson Street, Perry, Florida 32347, pursuant to FSA § 45,031, using the following method:
ANY PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS MUST FILE A CLAIM WITHIN 60 DAYS AFTER THE SALE.
Dated:  May 18, 2015
ANNIE MAE MURPHY
CLERK OF THE COURT
By: Marti Lee, DC
As Deputy Clerk
5/20, 5/27

IN THE CIRCUIT COURT OF THE THIRD JUDICIAL CIRCUIT IN AND FOR TAYLOR COUNTY, FLORIDA
CASE NO. 62-2012-CA-000004
SUNTRUST MORTGAGE, INC.
Plaintiff,
v.
RIGOBERTO PITA; UNKNOWN SPOUSE OF RIGOBERTO PITA; UNKNOWN TENANT 1; UNKNOWN TENANT 2; AND ALL UNKNOWN PARTIES CLAIMING BY, THROUGH, UNDER OR AGAINST THE ABOVE NAMED DEFENDANT(S), WHO (IS/ARE) NOT KNOWN TO BE DEAD OR ALIVE, WHETHER SAID UNKNOWN PARTIES CLAIM AS HEIRS, DEVISEES, GRANTEES, ASSIGNEES, LIENORS, CREDITORS, TRUSTEES, SPOUSES, OR OTHER CLAIMANTS; MANHEIM AUTOMOTIVE FINANCIAL SERVICES, INC.
Defendants.
__________/
NOTICE OF SALE
Notice is hereby given that, pursuant to the Summary Final Judgment of Foreclosure entered on May V^T, 2015, in this cause, in the Circuit Court ofTaylor County, Florida, the clerk shall sell the property situated in Taylor County, Florida, described as:
COMMENCE AT THE NORTHWEST CORNER OF THE NW 1/4 OF THE SW 1/4 OF SECTION 35, TOWNSHIP 3 SOUTH, RANGE 7 EAST, AND RUN N 89°49’10” E ALONG SAID FORTY LINE A DISTANCE OF 281.91 FEET TO THE EASTERLY RIGHT OF WAY LINE OF THE SOUTH GEORGIA RAILROAD;
THENCE RUN S 13°14’08” E ALONG SAID RIGHT OF WAY LINE A DISTANCE OF 51.33 FEET TO THE SOUTH RIGHT OF WAY LINE OF A COUNTY GRADED ROAD; THENCE CONTINUE S 13°14’08” E ALONG SAID RIGHT OF WAY LINE A DISTANCE OF 1346.21 FEET; THENCE RUN N 88°58’10” E A DISTANCE OF 922.76 FEET FOR A POINT OF BEGINNING; THENCE CONTINUE N 88°58’10” E A DISTANCE OF 230.69 FEET TO THE WESTERLYRIGHT OF WAY LINE OF U.S. HIGHWAY #221; THENCE RUN S 15°09’57” E ALONG SAID RIGHT OF WAY LINE A DISTANCE OF 442.95 FEET; THENCE RUN S 88°44’19” W, A DISTANCE OF 221.80 FEET; THENCE RUN IN A SOUTHWESTERLY DIRECTION ALONG THE ARC OF A CURVE CONCAVED TO THE SOUTH, A CHORD BEARING OF S 87°23’11” W A DISTANCE OF 11.23 FEET; THENCE RUN N 14°4T29″ W A DISTANCE QF 443.4 FEET TO THE POINT OF BEGINNING. LESS AND EXCEPT ROAD RIGHT OF WAY, AND IS LOCATED IN SECTION 35, TOWNSHIP 3 SOUTH, RANGE 7 EAST, TAYLOR COUNTY, FLORIDA.
AND
LOT 4, BLOCK C, FORTNER SUBDIVISION, A SUBDIVISION ACCORDING TO THE PLAT THEREOF AS RECORDED IN PLAT BOOK 1, PAGE 178, PUBLIC RECORDS OF TAYLOR COUNTY, FLORIDA.
AND
LOT 6, BLOCK C, FORTNER SUBDIVISION, A SUBDIVISION ACCORDING TO THE PLAT THEREOF as RECORDED IN PLAT BOOK 1, PAGE 178, PUBLIC RECORDS OF TAYLOR COUNTY, FLORIDA.
TOGETHER WITH THAT CERTAIN 2002 SCHULTZ DOUBLEWIDE MOBILE HOME WITH VIN #HOGA20K03613A, TITLE #85419273 AND VIN #HOGA20K03613B, TITLE #85419384.
a/k/a 4207 N. US 221, PERRY, FL 32347-9162
at public sale, to the highest and best bidder, for cash, on the West Side of The Taylor County Courthouse, 108 North Jefferson Street, Perry, FL 32347, on June 16, 2015 beginning at 11:00 AM.
If you are a person claiming a right to funds remaining after the sale, you must file a claim with the clerk no later than 60 days after the sale. If you fail to file a claim you will not be entitled to any remaining funds.
Dated this 18 day of May, 2015.
Annie Mae Murphy
Clerk of the Circuit court
By: Marti Lee, DC
Deputy Clerk
IF YOU ARE A PERSON WITH A DISABILITY AND YOU NEED ANY ACCOMMODATION IN ORDER TO PARTICIPATE IN THIS PROCEEDING, YOU ARE ENTITLED, AT NO COST TO you, TO THE PROVISION OF CERTAIN ASSISTANCE. PLEASE CONTACT ANNIE MAE MURPHY, CLERK OF THE COURT, AT P.O. BOX 620, PERRY, FL 32348, TELEPHONE (850) 838-3506 WITHIN TWO (2) WORKING DAYS OF YOUR RECEIPT OF THIS NOTICE. IF YOU ARE HEARING OR voice IMPAIRED, CALL 1-800-955-8771.
5/20, 5/27

IN THE CIRCUIT COURT, THIRD JUDICIAL CIRCUIT, IN AND FOR TAYLOR COUNTY FLORIDA
Case No. 2015-242-CP
IN RE: THE ESTATE OF
JOE WILLIAM PARKER,
Deceased.
NOTICE TO CREDITORS TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE:
The administration of the estate of JOE WILLIAM PARKER, deceased File Number: 2015-242-CP, is pending in the Circuit Court for Taylor County, Florida, Probate Division, the address of which is Taylor County Coin-mouse, Post Office Box 620, Perry, Florida 32348. The names and addresses of the personal representative and that personal representative’s attorney are set forth below.
ALL INTERESTED PERSONS ARE NOTIFIED THAT:
All creditors of the decedent and other persons having claims or demands against Decedent’s .estate on whom a copy of this notice has been served, must file their claims with this Court WITHIN THE LATER OF THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons having claims or demands against decedents estate must file their claims with this court WITHIN THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS, DEMANDS NOT SO FILED WILL BE FOREVER BARRED.
The date of the first publication of this Notice is May 20, 2015.
Subsequent date of publication is May 27, 2015.
Sandra F. Wetherington Personal Representative 4860 Roping Lane Perry, Florida 32347
John R.. Weed
Attorney for Personal Representative
605 S. Jefferson Street
Perry, Florida 32347
(850)838-1773
FBN: 121530
5/20, 5/27

IN THE CIRCUIT COURT, THIRD JUDICIAL CIRCUIT, IN AND FOR TAYLOR COUNTY FLORIDA
Case No. 2015-197-CP
IN RE: THE ESTATE OF
THOMAS SCOTT KLIENBACK.
Deceased.
_________/
NOTICE TO CREDITORS TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE:
The ancillary administration of the estate of THOMAS SCOTT KLIENBACK, deceased File Number: 2015-197-CP, is pending in the Circuit Court for Taylor County, Florida, Probate Division, the address of which is Taylor County Courthouse, Post Office Box 620, Perry, Florida 32348. The names and addresses of the ancillary personal representative and that personal representative’s attorney are set forth below.
ALL INTERESTED PERSONS ARE NOTIFIED THAT:
All creditors of the decedent and other persons having claims or demands against Decedent’s .estate on whom a copy of this notice has been served, must file their claims with this Court WITHIN THE LATER OF THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons having claims or demands against decedents estate must file their claims with this court WITHIN THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS, DEMANDS NOT SO FILED WILL BE FOREVER BARRED.
The date of the first publication of this Notice is May 20, 2015.
Subsequent date of publication is May 27, 2015.
Donald Klienback
Ancillary Personal Representative
11 Fishing Creek Road
Cape May Court house New Jersey 08219
John R.. Weed
Attorney for Ancillary Personal Representative
605 S. Jefferson Street
Perry, Florida 32347
(850)838-1773
FBN: 121530
5/20, 5/27

Taylor Storage Center
3498 Hwy 19 S. Suite 1
Perry, FL 32348
850-223-1455
Auction sale Notice
Jennifer Holton, Unit 2-47
Amanda Sutton, Unit 3-19
Montray Gross, Unit 3-22
Matt Sadler, Unit 3-39
Rodriquez Jackson, Unit 3-44
richard Paris, open storage
Robert Kellow, Units 4-36, 37, 38, 41, 42, 4A-19, 21, 22, 23, 25, 26, 27, 28, 29.
Taylor Storage Center, 3498 Hwy. 19 S. Suite 1, Perry, FL 32348, has possessory lien on all of the goods stored in the prospective units above. All these items of personal prperty are being sold pursuant to the assertion of the lien on Jaune 6, 2015 at 10 a.m. in order to collect the amounts due from you. The sale will take place at 3498 Hwy 19 S. Suite 1, Perry, FL 32348.
5/20, 5/27

Notice is hereby given to
Anthony Michael Jenkins. Unless payment is made on  1998 Mercury Grand Marquis, VIN: 2MEFM74W5WX676250 for tow & storage charges on  05/11/2015. Vehicle will be auctioned on
the 16TH day of  JUNE 2015 , at 10 a.m. at Thomas Chevrolet
2128 S. Byron Butler Pkwy, Perry, FL
(850) 584-6221 per F.S. 713.78
5/20

NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN, that Taylor County Commissioners the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, year of issuance, description of the property and the names in which the property was assessed are as follows:
Certificate Number 1222
Year of Issuance   2012
Description of Property:
Parcel Number R08323-300
Commence at the East Right-of-way of Highway 19 and the South Boundary line of the Southwest 1/4 of the Southeast 1/4 of Section 06, Township 05 South, Range 08 East; thence run North 26D West 800 feet; thence run North 63D East 350 feet; thence run North 26D West 178.31 feet for a Point of Beginning. Thence run North 26 D West 20239 feet; thence run North 70D East 100.81 feet; thence run South 26D East 195.01 feet; thence run South 66D West 100.12 feet to the Point of Beginning. Containing 0.46 acres more or less. Recorded in the official records 567, page 13.
Name in which assessed Francis L. King
Said property being in the County of Taylor, State of Florida.
Unless such certificate shall be redeemed according to law, the property
described shall be sold to the highest bidder at the courthouse door on the 26th day of May, 2015 at 11:00 o’clock a.m.
Dated this 22nd day of April, 2015
Signature:
Annie Mae Murphy
Clerk of Circuit Court
Taylor County, Florida
4/29, 5/6, 5/13, 5/20

NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN, that John Cloyd the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, year of issuance, description of the property and the names in which the property was assessed are as follows:
Certificate Number 1493
Year of Issuance   2012
Description of Property:
Parcel Number R10112-700
Lot 1 and South 1/2 of lot 2, unit 3 of the Steinhatchee Ancient Oaks Subdivision. Containing 2.04 acres more or less. Recorded in official records 541, page 124.
Name in which assessed Edward E. Curci
Said property being in the County of Taylor, State of Florida.
Unless such certificate shall be redeemed according to law, the property
described shall be sold to the highest bidder at the courthouse door on the 26th day of May, 2015 at 11:00 o’clock a.m.
Dated this 22nd day of April, 2015
Signature:
Annie Mae Murphy
Clerk of Circuit Court
Taylor County, Florida
4/29, 5/6, 5/13, 5/20

NOTICE OF APPLICATION FOR TAX DEED
NOTICE IS HEREBY GIVEN, that John Cloyd the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, year of issuance, description of the property and the names in which the property was assessed are as follows:
Certificate Number 1483
Year of Issuance   2012
Description of Property:
Parcel Number R10112-525
Lot 41, Unit 1 of the Steinhatchee Ancient Oaks Subdivision. Containing 0.93 acres more of less. Recorede in official records 536, page 350.
Name in which assessed Edward E. Curci
Said property being in the County of Taylor, State of Florida.
Unless such certificate shall be redeemed according to law, the property
described shall be sold to the highest bidder at the courthouse door on the 26th day of May, 2015 at 11:00 o’clock a.m.
Dated this 22nd day of April, 2015
Signature:
Annie Mae Murphy
Clerk of Circuit Court
Taylor County, Florida
4/29, 5/6, 5/13, 5/20